Terms & Conditions

Handy Manny's LLC 1040 Monarch St Unit 327, Lexington, KY 40513 Phone: (859) 551-5302 · Email: manny@handymannys.biz · Web: handymannysky.com

Effective Date: June 18, 2026 Last Updated: June 18, 2026

1. Agreement to These Terms

These Terms and Conditions ("Terms") govern your access to and use of the website located at handymannysky.com and any associated subdomains, pages, forms, and digital properties (collectively, the "Site"), as well as all construction, remodeling, contracting, consulting, estimating, and related services (collectively, the "Services") offered by Handy Manny's LLC, a Kentucky limited liability company ("Handy Manny's," "Company," "we," "us," or "our").

By accessing or using the Site, requesting an estimate, submitting any form, communicating with us by phone, text, or email, or entering into any written agreement, work order, proposal, or contract with us (each, a "Contract"), you ("you," "Client," or "user") acknowledge that you have read, understood, and agree to be bound by these Terms. If you do not agree to these Terms, do not use the Site or engage our Services.

These Terms are incorporated by reference into every Contract between you and Handy Manny's. Where a signed Contract references "our website terms," "full terms and conditions," or similar language, that reference means these Terms, identified by title, the URL https://handymannysky.com/terms-and-conditions, and the effective/version date set forth above. The version of these Terms in effect on the date a Contract is signed governs that Contract unless the parties sign a later written amendment. In the event of a direct conflict between a signed Contract and these Terms, the express written terms of the signed Contract control as to the specific subject of that conflict; in all other respects these Terms apply.

2. Definitions

• "Services" means any labor, materials, project management, design, estimating, consultation, remodeling, renovation, construction, repair, restoration, or related work performed or offered by Handy Manny's.
• "Project" means a specific scope of Services described in a Contract, proposal, estimate, or work order.
• "Estimate" means a non-binding, good-faith projection of anticipated cost and scope.
• "Proposal" / "Contract" means a written document describing scope, price, and terms that, once signed or accepted, becomes a binding agreement.
• "Change Order" means a written modification to the scope, price, or schedule of a Project.
• "Site" means the website and digital properties described in Section 1.

3. Company Information; Licensing and Insurance

Handy Manny's LLC is a licensed general contractor operating in the Commonwealth of Kentucky, serving Lexington and Central Kentucky for residential and small commercial work, with coverage across Kentucky for qualifying large commercial construction and property development projects.

Handy Manny's currently carries approximately $2 million in general liability coverage and workers' compensation coverage, subject to policy terms, limits, exclusions, and renewal. Proof of current licensing and insurance is available on request. Nothing on the Site or in these Terms constitutes a guarantee of any particular license classification for work outside our stated service categories; specialized work (e.g., licensed electrical, plumbing, or HVAC work) is performed by appropriately licensed subcontractors or trade partners where required by law.

4. Estimates, Proposals, and Pricing

4.1 Estimates Are Non-Binding. All estimates are provided in good faith based on information available at the time, including site conditions visible or disclosed during a walkthrough. An estimate is not a fixed-price guarantee unless expressly stated in writing as a "fixed-price" or "guaranteed" Contract.

4.2 Validity Period. Unless otherwise stated, estimates and proposals are valid for thirty (30) days from the date issued. Material prices, labor availability, and market conditions may change; we reserve the right to revise pricing after the validity period or upon discovery of conditions not reasonably ascertainable at the time of estimate.

4.3 Concealed and Unforeseen Conditions. Construction frequently uncovers conditions not visible during initial inspection (for example: hidden water damage, mold, structural deficiencies, code violations, outdated wiring or plumbing, or pest damage). Such conditions are outside the scope of any estimate and will be addressed by Change Order at additional cost. Hazardous and regulated materials are addressed separately in Section 8.

4.4 Allowances. Where a Contract includes an allowance (a budgeted amount for items not yet selected, such as fixtures, tile, or finishes), the final price will be adjusted up or down based on actual selected-item cost. Selections exceeding the allowance are the Client's responsibility.

4.5 Free Estimates. Where we advertise "free estimates," this applies to standard pre-project assessments within our service area. Complex assessments, destructive investigation, engineering, or third-party reports may incur a fee disclosed in advance.

5. Contracts, Scope of Work, and Change Orders

5.1 Binding Contract. Services are performed only under a written Contract describing the scope, price, payment schedule, and timeline. Verbal agreements are not binding on Handy Manny's unless subsequently confirmed in writing.

5.2 Scope Limitations. We will perform only the work expressly described in the Contract. Anything not specifically included is excluded.

5.3 Change Orders. Any addition, deletion, or modification to the agreed scope must be documented in a written Change Order signed or approved (including by electronic or text/email confirmation) by both parties before the changed work proceeds, except in emergencies necessary to protect health, safety, or property. Change Orders may affect both price and schedule.

5.4 Client-Supplied Materials and Third Parties. If the Client supplies materials or hires separate contractors, Handy Manny's is not responsible for the quality, suitability, timeliness, or warranty of such materials or work, or for delays they cause.

6. Payment Terms

6.1 Payment Schedule. Payment is due according to the schedule in the Contract, which may include a deposit, progress/milestone payments, and a final payment upon substantial completion.

6.2 Deposits. Deposits are applied to the Project and may be used to secure scheduling, order materials, and mobilize labor. Deposit refundability is governed by the Contract and Section 12 (Cancellation), including any non-waivable statutory cancellation rights.

6.3 Late Payment. Payments not received by their due date may accrue interest at the lesser of one and one-half percent (1.5%) per month (18% per annum) or the maximum rate permitted by Kentucky law, unless a different rate, payment timing, or notice requirement is mandated by applicable Kentucky construction prompt-payment law, in which case that law controls. The Client is responsible for all reasonable costs of collection, including attorneys' fees and court costs to the extent permitted by law.

6.4 Suspension for Non-Payment. We may suspend work without liability if any payment is past due, and we are entitled to an equitable extension of time and recovery of reasonable remobilization costs.

6.5 Mechanic's and Materialman's Liens. Kentucky law may give Handy Manny's, its subcontractors, material suppliers, equipment providers, and other eligible claimants mechanic's or materialman's lien rights for unpaid labor, materials, equipment, or services furnished to improve real property. Lien rights, required notices, filing deadlines, owner-occupied residential limitations (including special rules for single- and double-family owner-occupied dwellings), lien-amount limits, and enforcement deadlines are governed by KRS Chapter 376. This notice is provided for informational purposes. Nothing in these Terms waives any lien right except through a written partial or final lien waiver issued in connection with payment, to the extent permitted by Kentucky law.

6.6 Returned Payments. A fee may be charged for any returned, declined, or reversed payment, to the extent permitted by law.

7. Scheduling, Delays, and Access

7.1 Schedule Estimates. Project timelines are good-faith estimates, not guarantees. Completion dates may be affected by weather, material availability, permitting, inspections, concealed conditions, Change Orders, Client decisions/selections, and other factors.

7.2 Force Majeure. We are not liable for delay or failure to perform caused by events beyond our reasonable control, including acts of God, severe weather, fire, flood, pandemic, labor shortages, supply-chain disruption, governmental action, or permitting delays.

7.3 Site Access. The Client must provide safe, timely, and unobstructed access to the work area, along with reasonable access to water and electricity where needed. Delays caused by lack of access are the Client's responsibility and may result in schedule and cost adjustments.

8. Permits, Codes, Inspections, and Hazardous Materials

8.1 Permits and Codes. Where required, we will obtain applicable building permits as agreed in the Contract. The Client is responsible for providing accurate property information and for any homeowner-association, deed, or private restriction approvals. Work will be performed to applicable building codes in effect at the time of permitting. Code changes, special inspections, or jurisdictional requirements discovered after work begins may require Change Orders.

8.2 Hazardous or Regulated Materials. Unless expressly included in the Contract, Handy Manny's scope excludes testing, abatement, remediation, encapsulation, transport, and disposal of hazardous or regulated materials, including lead-based paint, asbestos, mold, crystalline silica, sewage, biological contaminants, contaminated soils, fuel, chemicals, and similar hazards. The Client must disclose all known or suspected hazards and provide all related reports in the Client's possession or control. If suspected hazardous or regulated materials are encountered, we may stop affected work until appropriate testing, abatement, permits, notices, controls, and licensed specialists are arranged, and the price and schedule will be adjusted by Change Order. Work involving regulated materials will be performed only by properly qualified persons and in compliance with applicable law, including the EPA Renovation, Repair and Painting (RRP) Rule for pre-1978 housing and child-occupied facilities, EPA asbestos NESHAP requirements, and applicable OSHA standards.

9. Warranty and Disclaimers

9.1 Workmanship Warranty. Unless a different period is stated in the Contract, Handy Manny's warrants its workmanship against defects in labor for a period of one (1) year from the date of substantial completion. This warranty is the Client's sole and exclusive express workmanship warranty.

9.2 Manufacturer Warranties. Materials, fixtures, appliances, and products are covered only by their respective manufacturer warranties, which are passed through to the Client. We make no independent warranty on manufactured goods.

9.3 Warranty Exclusions. The workmanship warranty does not cover: (a) normal wear and tear, settling, or shrinkage; (b) damage from misuse, neglect, abuse, or failure to perform routine maintenance; (c) damage from alterations or repairs performed by others; (d) acts of God, weather events, or casualty; (e) Client-supplied materials or Client-directed methods; (f) cosmetic variations inherent in natural or handcrafted materials; or (g) work where final payment has not been received.

9.4 Warranty Claims. Warranty claims must be submitted in writing to manny@handymannys.biz or by mail to the address above, with a reasonable opportunity for us to inspect and remedy before the Client engages others.

9.5 DISCLAIMER. EXCEPT FOR THE EXPRESS LIMITED WORKMANSHIP WARRANTY IN SECTION 9.1 AND ANY WARRANTIES, REMEDIES, OR DUTIES THAT CANNOT BE WAIVED UNDER APPLICABLE LAW, HANDY MANNY'S DISCLAIMS ALL OTHER WARRANTIES, WHETHER EXPRESS, IMPLIED, OR STATUTORY, INCLUDING ANY IMPLIED WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, AND NON-INFRINGEMENT, TO THE FULLEST EXTENT PERMITTED BY KENTUCKY LAW. NOTHING IN THESE TERMS WAIVES ANY NON-WAIVABLE STATUTORY, CODE, SAFETY, HABITABILITY, IMPLIED NEW-HOME CONSTRUCTION, OR CONSUMER-PROTECTION OBLIGATION.

10. Limitation of Liability

10.1 Cap on Liability. TO THE FULLEST EXTENT PERMITTED BY LAW, HANDY MANNY'S TOTAL AGGREGATE LIABILITY ARISING OUT OF OR RELATED TO ANY PROJECT, THE SERVICES, OR THESE TERMS SHALL NOT EXCEED THE TOTAL AMOUNT ACTUALLY PAID BY THE CLIENT TO HANDY MANNY'S FOR THE SPECIFIC PROJECT GIVING RISE TO THE CLAIM.

10.2 No Consequential Damages. IN NO EVENT SHALL HANDY MANNY'S BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, PUNITIVE, OR EXEMPLARY DAMAGES, INCLUDING LOST PROFITS, LOSS OF USE, LOSS OF BUSINESS, OR DIMINUTION IN VALUE, EVEN IF ADVISED OF THE POSSIBILITY OF SUCH DAMAGES.

10.3 Carveouts. The limitations in this Section do not apply to: (a) liability that cannot be limited by law; (b) gross negligence, reckless, willful, wanton, or intentional misconduct; (c) personal injury or death caused by negligence to the extent non-waivable; (d) violations of applicable safety statutes, building codes, consumer-protection laws, lien laws, or telecommunications laws; (e) fraud or intentional misrepresentation; (f) amounts covered by available insurance proceeds; or (g) Handy Manny's payment obligations to subcontractors or suppliers.

10.4 Site Use. The Site and its content are provided for general information only and do not constitute professional, engineering, or legal advice. We do not warrant that the Site will be uninterrupted, error-free, or free of harmful components.

10.5 Basis of the Bargain. The limitations in Sections 9 and 10 are an essential part of the agreement between you and Handy Manny's, and our pricing reflects this allocation of risk, subject to the carveouts in Section 10.3.

11. Indemnification

To the fullest extent permitted by law, the Client agrees to indemnify, defend, and hold harmless Handy Manny's, its members, employees, subcontractors, and agents from any claims, damages, liabilities, losses, and expenses (including reasonable attorneys' fees) arising from: (a) the Client's breach of these Terms or a Contract; (b) inaccurate property information or undisclosed conditions provided by the Client; (c) Client-supplied materials or Client-directed work; (d) the acts or omissions of third parties hired directly by the Client; or (e) the Client's violation of any law or third-party right.

This indemnity applies only to the extent caused by the Client or by persons or entities for whom the Client is legally responsible, and does not require the Client to indemnify or hold harmless Handy Manny's for Handy Manny's own negligence, willful misconduct, violation of law, or the negligence of Handy Manny's agents or employees to the extent such indemnity is void or unenforceable under Kentucky law, including KRS 371.180.

12. Cancellation and Right to Rescind

12.1 Statutory Cancellation Rights. Some consumer transactions, including certain in-home, home-solicitation, or temporary-location sales, may be subject to federal or Kentucky cancellation rights. Where such a right applies, the Contract will include the required notice of cancellation rights, seller information, the cancellation deadline, and any required cancellation forms. These Terms do not shorten, waive, or limit any non-waivable statutory cancellation right.

12.2 Cancellation After Commencement; Statutory Rights Control. Except where a non-waivable federal or Kentucky cancellation right applies, if the Client cancels after work has begun, materials have been ordered, or special scheduling has occurred, the Client is responsible for the value of work performed, non-returnable or custom-ordered materials, restocking fees, permit/design/third-party charges, and reasonable demobilization costs, which may be deducted from any deposit. If a transaction is a covered home-solicitation sale or other transaction subject to a statutory right of cancellation, the statutory notice, refund, no-compensation, and cancellation procedures control over this Section. No provision of these Terms waives any non-waivable right to cancel.

12.3 Termination by Handy Manny's. We may terminate or suspend a Project for non-payment, unsafe conditions, denial of access, or material breach by the Client, and recover payment for work performed plus reasonable costs.

13. Residential Construction Defect Notice

For contracts involving construction of a residence, Kentucky law provides important procedures before a homeowner may file a lawsuit for defective construction. The following statutory notice is provided pursuant to KRS 411.260:

SECTIONS 411.250 TO 411.260 OF THE KENTUCKY REVISED STATUTES CONTAIN IMPORTANT REQUIREMENTS YOU MUST FOLLOW BEFORE YOU MAY FILE A LAWSUIT FOR DEFECTIVE CONSTRUCTION AGAINST THE BUILDER OF YOUR HOME. YOU MUST DELIVER TO THE BUILDER A WRITTEN NOTICE OF ANY CONSTRUCTION CONDITIONS YOU ALLEGE ARE DEFECTIVE AND PROVIDE YOUR BUILDER THE OPPORTUNITY TO MAKE AN OFFER TO REPAIR OR PAY FOR THE DEFECTS. YOU ARE NOT OBLIGATED TO ACCEPT ANY OFFER MADE BY THE BUILDER. THERE ARE STRICT DEADLINES AND PROCEDURES UNDER STATE LAW, AND FAILURE TO FOLLOW THEM MAY AFFECT YOUR ABILITY TO FILE A LAWSUIT.

14. Marketing, Media, Photography, and Promotional Use

14.1 Grant of Rights. By entering into a Contract or engaging our Services, the Client grants Handy Manny's LLC a perpetual, irrevocable (except for a timely written opt-out under Section 14.6 and except as required by law), worldwide, royalty-free, and transferable right and license to photograph, film, record, capture, reproduce, edit, publish, display, and distribute images, video, audio, drone footage, time-lapse, before-and-after content, renderings, and descriptions of the Project, the work site, completed work, and the general project location for marketing, advertising, promotional, portfolio, educational, social media, website, and business-development purposes, across any current or future media or platform.

14.2 Scope of Permitted Use. This grant includes the right to use: (a) photographs and video of the interior and exterior work performed; (b) the project type, scope summary, neighborhood, city, and general location (e.g., "a kitchen remodel in Lexington, KY"); and (c) testimonials, reviews, and quotes the Client voluntarily provides. Unless the Client expressly authorizes it in writing, we will not publish the Client's full street address, full name (beyond first name or initials), financial details, or other sensitive personal information.

14.3 Identifiable Persons; Minors; Third Parties. We will not intentionally publish identifiable images, video, or audio of any person other than the Client without a separate written release from that person, and, for minors, from a parent or legal guardian. The Client represents that the Client has authority to permit project-site photography of the work areas, but the Client does not grant rights in the likeness, voice, privacy, publicity, trademark, confidential information, or intellectual-property rights of neighbors, tenants, guests, employees, children, HOA personnel, school or government staff, or any other third party.

14.4 Privacy-Sensitive Content. We may blur, crop, redact, or omit faces, license plates, security systems, street numbers, mail, family photos, minors, valuables, computer screens, documents, access credentials, and other sensitive details. We will not publish the full street address or security-sensitive location details without written approval.

14.5 Audio. We will not intentionally publish recorded private conversations for marketing without the express consent of the recorded speakers.

14.6 Opt-Out. The Client may opt out of the marketing-use rights in this Section, in whole or in part, by submitting a written request to manny@handymannys.biz before Project commencement. Upon a valid opt-out, we will not capture or publish content from that Project beyond what is necessary to perform the work, and we will make commercially reasonable efforts to remove previously published content going forward (recognizing that some distributed or third-party-cached content may not be fully retrievable).

14.7 Restricted and Federal/Institutional Projects. For any project involving governmental, federal, defense, school, healthcare, institutional, leased, tenant-occupied, NDA-bound, security-sensitive, or otherwise restricted property, no marketing capture or publication will occur unless the parties first document written media-clearance instructions identifying: (1) whether capture is allowed at all; (2) what locations, people, equipment, documents, signage, logos, addresses, and security features must be excluded or blurred; (3) who must approve content before publication; and (4) whether the project may be named, described generally, or not referenced at all. The Client must disclose any such restriction in writing before work begins.

14.8 Drone Operations. Drone footage may be captured only by properly authorized operators and only in compliance with applicable FAA, state, local, site-safety, privacy, and property-access requirements. We will not intentionally capture or publish close-up images of neighboring properties, non-participants, license plates, security-sensitive areas, or private activities unrelated to the Project.

14.9 Ownership of Marketing Content. All marketing and promotional content created by or for Handy Manny's — including photographs, video, edited media, captions, and graphics — is and remains the sole property of Handy Manny's. Handy Manny's will obtain appropriate ownership, assignment, work-made-for-hire, or license rights from photographers, videographers, drone operators, editors, employees, subcontractors, and other contributors whose content it uses for marketing. Nothing in these Terms transfers ownership of such content to the Client.

14.10 Client-Provided Content. If the Client provides Handy Manny's with photographs, reviews, or other content, the Client represents they have the right to do so and grants Handy Manny's the right to use it for the purposes in this Section.

14.11 No Obligation. Nothing in this Section obligates Handy Manny's to use, publish, or retain any particular content.

15. Communications, Calls, Texting, and SMS Consent (A2P 10DLC)

15.1 Consent to Contact. By providing your phone number or email and by affirmatively opting in through our website chat widget, form, or other designated opt-in method, you consent to receive communications from Handy Manny's related to your inquiry, estimate, project, scheduling, and service follow-up.

15.2 SMS/Text Program Terms. By providing your mobile number and affirmatively opting in to Handy Manny's text messaging program, you agree to receive text messages from Handy Manny's LLC about your inquiry, estimate, scheduling, project updates, service follow-up, and, only if separately selected, promotional or marketing messages. Message frequency varies. Message and data rates may apply. Reply STOP to cancel, HELP for help, or contact us at (859) 551-5302 or manny@handymannys.biz. Consent to marketing texts or calls is not a condition of purchase. Carriers are not liable for delayed or undelivered messages. We do not sell, rent, share, or transfer mobile opt-in data, SMS consent, or phone numbers to third parties, affiliates, or lead generators for marketing or promotional purposes.

15.3 Recorded and Transcribed Communications. We may record or transcribe calls, virtual meetings, and project walkthroughs for quality, training, scheduling, documentation, and dispute-prevention purposes after providing notice where required. Kentucky is a one-party-consent jurisdiction; if a recording would require additional consent under applicable law, we will obtain that consent or not record.

15.4 Consent Not a Condition of Purchase. Your consent to marketing texts or calls is not a condition of purchasing any Services. Opting out of marketing texts does not affect your Contract or your ability to receive Services.

16. Privacy

Your use of the Site and our Services is also governed by our Privacy Policy, which is incorporated into these Terms by reference and available at handymannysky.com/privacy-policy. The Privacy Policy describes how we collect, use, and protect your information, including the categories of data we collect, the purposes for which it is used, our security and retention practices, how to request access or deletion, and our commitment that mobile opt-in information and SMS consent are not shared with third parties or affiliates for marketing or promotional purposes.

17. Intellectual Property; Site Use

All content on the Site — including text, graphics, logos, the "Handy Manny's" name and marks, images, video, and design — is owned by or licensed to Handy Manny's and protected by applicable intellectual-property laws. You may not copy, reproduce, republish, frame, collect by automated means, or exploit any Site content without our prior written permission, except for ordinary personal, non-commercial viewing. We grant no license to our marks by implication.

Prohibited Uses. You agree not to: (a) use the Site for any unlawful purpose; (b) attempt to gain unauthorized access to our systems; (c) introduce malware or disruptive code; (d) use automated means to harvest data; or (e) interfere with the Site's operation.

18. Third-Party Links and Subcontractors

The Site may contain links to third-party websites or services provided for convenience; we do not endorse and are not responsible for their content or practices. We may engage qualified subcontractors and trade partners to perform portions of the Services; we remain the Client's primary point of contact, but manufacturer and trade-specific warranties pass through as described in Section 9.

19. No Affiliate Marketing; No Sale of Leads

Handy Manny's does not engage in affiliate-marketing lead resale and does not buy or sell consumer leads or contact information for third-party marketing purposes. Information you provide is used to serve your inquiry and deliver our Services.

20. Customer Property; Stored and Abandoned Materials

The Client is responsible for removing or protecting personal property from work areas before work begins. Removed fixtures, debris, demolition materials, and excess materials will be disposed of unless the Contract states otherwise or the Client requests retention in writing before removal. Materials purchased for the Project may be stored on-site or off-site and remain subject to the payment terms of the Contract.

21. Accessibility

Handy Manny's strives to make its website accessible and usable. If you have difficulty accessing any content or functionality, contact manny@handymannys.biz or (859) 551-5302 and we will make reasonable efforts to provide the information or service through an accessible alternative.

22. Dispute Resolution; Governing Law

22.1 Governing Law. These Terms and any Contract are governed by the laws of the Commonwealth of Kentucky, without regard to conflict-of-laws principles.

22.2 Good-Faith Resolution. The parties agree to first attempt to resolve any dispute through direct, good-faith negotiation. If unresolved, the parties may agree to non-binding mediation before pursuing other remedies.

22.3 Venue. Subject to any binding arbitration provision expressly included in a signed Contract, if any, the state and federal courts located in Fayette County, Kentucky shall have exclusive jurisdiction and venue over any dispute, and the parties consent to such jurisdiction.

22.4 Attorneys' Fees. In any action to enforce these Terms or a Contract, the prevailing party is entitled to recover reasonable attorneys' fees and costs to the extent permitted by law.

22.5 Limitation Period. To the extent permitted by law, any claim under the express one-year workmanship warranty must be submitted in writing within the warranty period. Any lawsuit based solely on the express workmanship warranty must be filed within one (1) year after Handy Manny's final written denial of the warranty claim or completion of any attempted warranty repair, whichever is later. This limitation does not apply to claims that cannot be shortened by agreement, including claims involving personal injury, fraud, statutory consumer rights, lien rights, construction-defect notice or tolling rights, gross negligence, willful misconduct, latent defects, or other non-waivable rights.

23. General Provisions

23.1 Entire Agreement. These Terms, together with the applicable Contract and Privacy Policy, constitute the entire agreement between the parties regarding the subject matter and supersede all prior understandings.

23.2 Severability. If any provision is held unenforceable, the remaining provisions remain in full force, and the unenforceable provision will be modified to the minimum extent necessary to make it enforceable.

23.3 No Waiver. Our failure to enforce any provision is not a waiver of our right to do so later.

23.4 Assignment. The Client may not assign a Contract without our written consent. We may assign our rights and obligations to a successor or affiliate.

23.5 Modifications to Terms. We may update these Terms from time to time. The "Last Updated" date reflects the most recent version, and Handy Manny's preserves an archived copy of each published version. Continued use of the Site or Services after changes constitutes acceptance. The version in effect at the time a Contract is signed governs that Contract unless the parties agree otherwise in writing.

23.6 Electronic Acceptance. You agree that electronic signatures, click-acceptance, and email/text confirmations are valid and binding to the same extent as a handwritten signature.

23.7 Headings. Section headings are for convenience only and do not affect interpretation.

24. Contact Us

Questions about these Terms or any Project may be directed to:

Handy Manny's LLC 1040 Monarch St Unit 327 Lexington, KY 40513 Phone: (859) 551-5302 Email: manny@handymannys.biz Web: handymannysky.com

These Terms are written to protect Handy Manny's LLC and to be clear and fair to our clients. Because laws change and individual situations vary, Handy Manny's recommends that this document be reviewed by a licensed Kentucky attorney before final publication, and periodically thereafter, to confirm it remains current with Kentucky contractor, consumer-protection, lien, hazardous-materials, and telecommunications (A2P/TCPA) law. For in-home consumer contracts, the signed paper Contract should attach the required Kentucky "BUYER'S RIGHT TO CANCEL" notice and any applicable federal cooling-off cancellation forms, and should incorporate these Terms by title, URL, and version date.